Terms of Service

1. Services

PONCHIELLI TRADING SRL provides:

• Interior design consultations
• Space planning and renovation services
• Custom furniture and finish specifications
• Project management for residential/commercial projects

2. Client Responsibilities

You agree to:

• Provide accurate property information and measurements
• Obtain necessary permits or approvals
• Secure the worksite during renovations
• Make timely decisions to avoid project delays

3. Fees & Payments

• 50% deposit required to commence design work
• Balance due upon project completion
• Additional charges for material upgrades or scope changes
• Late payments incur 2% monthly interest

4. Project Timeline

Estimated completion dates are not guaranteed. Delays caused by:

• Client decision-making
• Material availability
• Unforeseen structural issues

may extend the timeline without liability to PONCHIELLI TRADING SRL.

5. Intellectual Property

• Design concepts remain our property until full payment
• Unauthorized reproduction of plans is prohibited
• We retain the right to showcase completed projects in our portfolio

6. Limitation of Liability

We are not liable for:

• Pre-existing structural defects
• Damages caused by third-party contractors
• Design implementations not executed by our team

7. Termination

Either party may terminate with written notice:

• Client forfeits deposit if terminating after design approval
• We reserve the right to terminate for non-payment or unsafe worksite conditions

8. Governing Law

These terms are governed by Italian law. Any disputes shall be resolved in the courts of Italy.

9. Contact

For questions regarding these terms:

Email: [email protected]

Address: VIA G. CAVALCANTI 4 - 20063, Italy